Contractors` escape route blocked up
Language: English Series: Building ; 258(22) 28 May 1993, 34-35(2)Publication details: 1993Subject(s): Summary: Summarises "Balfour Beatty Building v Chestermount Properties" (1993), on the issue of calculation of liquidated damages for delay by the contractor, when a variation has been issued after the completion date. The court decision did not allow contractors to avoid liquidated damages in these circumstances.| Item type | Current library | Call number | Copy number | Status | Barcode | |
|---|---|---|---|---|---|---|
| Journal article | London Journal article | ABS48786 (Browse shelf(Opens below)) | 1 | Available | 68539-1001 |
Summarises "Balfour Beatty Building v Chestermount Properties" (1993), on the issue of calculation of liquidated damages for delay by the contractor, when a variation has been issued after the completion date. The court decision did not allow contractors to avoid liquidated damages in these circumstances.