An arbitrator overruled
Powell-Smith, V.
An arbitrator overruled - 1987 - Contract Journal 339(5629) 3 September 1987, 7(1) .
Discusses the case BFI Group of Companies Ltd v DCB Integration Systems Ltd (See WB2331-08) which concerned a challenge to an arbitrator`s award in a dispute arising under a JCT Minor Works Form . The judge ruled that liquidated damages should be awarded whether or not the employer suffers any actual loss.
MANAGEMENT-DISPUTE AVOIDANCE, MANAGEMENT AND RESOLUTION-DISPUTE MANAGEMENT AND RESOLUTION-ARBITRATION
BUILT ENVIRONMENT-BUILDING CONTRACT FORMS
CLAIMS
An arbitrator overruled - 1987 - Contract Journal 339(5629) 3 September 1987, 7(1) .
Discusses the case BFI Group of Companies Ltd v DCB Integration Systems Ltd (See WB2331-08) which concerned a challenge to an arbitrator`s award in a dispute arising under a JCT Minor Works Form . The judge ruled that liquidated damages should be awarded whether or not the employer suffers any actual loss.
MANAGEMENT-DISPUTE AVOIDANCE, MANAGEMENT AND RESOLUTION-DISPUTE MANAGEMENT AND RESOLUTION-ARBITRATION
BUILT ENVIRONMENT-BUILDING CONTRACT FORMS
CLAIMS