No great Sheikhs
Bingham, T
No great Sheikhs - 2002 - Building 267(8215) 15 March 2002, 60-61(2) .
Reviews "Solland International Ltd v Daraydan Holdings Ltd" (2002) in which the High Court enforced an adjudicator's award to a builder and refused to offset it against the employer's claim for liquidated damages. Compares it with the decision in "David McLean Housing Contractors Ltd v Swansea Housing Association Ltd" (2002) in which a deduction for liquidated damages was allowed.
LIQUIDATED DAMAGES
DAVID MCLEAN HOUSING CONTRACTORS LTD V SWANSEA HOUSING ASSOCIATION
SOLLAND INTERNATIONAL LTD V DARAYDAN HOLDINGS LTD
MANAGEMENT-DISPUTE AVOIDANCE, MANAGEMENT AND RESOLUTION-DISPUTE MANAGEMENT AND RESOLUTION-ALTERNATIVE DISPUTE RESOLUTION-ADJUDICATION
BUILT ENVIRONMENT-BUILDING CONTRACT FORMS
No great Sheikhs - 2002 - Building 267(8215) 15 March 2002, 60-61(2) .
Reviews "Solland International Ltd v Daraydan Holdings Ltd" (2002) in which the High Court enforced an adjudicator's award to a builder and refused to offset it against the employer's claim for liquidated damages. Compares it with the decision in "David McLean Housing Contractors Ltd v Swansea Housing Association Ltd" (2002) in which a deduction for liquidated damages was allowed.
LIQUIDATED DAMAGES
DAVID MCLEAN HOUSING CONTRACTORS LTD V SWANSEA HOUSING ASSOCIATION
SOLLAND INTERNATIONAL LTD V DARAYDAN HOLDINGS LTD
MANAGEMENT-DISPUTE AVOIDANCE, MANAGEMENT AND RESOLUTION-DISPUTE MANAGEMENT AND RESOLUTION-ALTERNATIVE DISPUTE RESOLUTION-ADJUDICATION
BUILT ENVIRONMENT-BUILDING CONTRACT FORMS