Mid Glamorgan CC v J Devonald Williams and Partner (Record no. 33860)

MARC details
000 -LEADER
fixed length control field 01654cab a2200253 4500
001 - CONTROL NUMBER
control field ABS45847
008 - FIXED-LENGTH DATA ELEMENTS--GENERAL INFORMATION
fixed length control field 090401t1992 xxu||||| |||| 00| 0 eng d
035 ## - SYSTEM CONTROL NUMBER
System control number (Sirsi) u55427
041 ## - LANGUAGE CODE
Language code of text/sound track or separate title eng
245 ## - TITLE STATEMENT
Title Mid Glamorgan CC v J Devonald Williams and Partner
260 ## - PUBLICATION, DISTRIBUTION, ETC.
Date of publication, distribution, etc. 1992
350 ## - PRICE (NR) (BK AM CF MU VM SE) [OBSOLETE]
Price 0
490 ## - SERIES STATEMENT
Series statement Construction Law Journal
Volume/sequential designation 8(1) 1992, 61-72(7)
520 ## - SUMMARY, ETC.
Summary, etc. ORB 17 September 1991. The plaintiff council, M, engaged the defendant architects, D, to design and supervise alteration and extension works on a college. Works were completed September 1984 and the final certificate was issued May 1986. In May 1988 M issued proceedings against D on the grounds that they had failed to supply information timeously, failed to warn of shortcomings in the design and appointed an inexperienced project architect, thereby delaying completion. M claimed additional preliminaries, loss caused by delay and disruption of the works and additional fluctuations. D requested further particulars which were issued in May 1991. D remained dissatisfied and requested more information and applied to strike out part of the claim on the grounds that paragraphs of the statement may prejudice, embarrass or delay the fair trial of the action and were an abuse of the process of the court. It was held that where a claim is made for extra costs incurred through delay as a result
650 ## - SUBJECT ADDED ENTRY--TOPICAL TERM
Topical term or geographic name entry element ALTERATIONS
650 ## - SUBJECT ADDED ENTRY--TOPICAL TERM
Topical term or geographic name entry element BUILT ENVIRONMENT-BUILDING CONTRACT FORMS
650 ## - SUBJECT ADDED ENTRY--TOPICAL TERM
Topical term or geographic name entry element CLAIMS
650 ## - SUBJECT ADDED ENTRY--TOPICAL TERM
Topical term or geographic name entry element CONTRACT CLAIMS
650 ## - SUBJECT ADDED ENTRY--TOPICAL TERM
Topical term or geographic name entry element DELAY
650 ## - SUBJECT ADDED ENTRY--TOPICAL TERM
Topical term or geographic name entry element LOSS AND EXPENSE
690 ## - LOCAL SUBJECT ADDED ENTRY--TOPICAL TERM (OCLC, RLIN)
Topical term or geographic name as entry element BUILDING AND CONSTRUCTION-CASE LAW
942 ## - ADDED ENTRY ELEMENTS (KOHA)
Suppress in OPAC 0
948 ## - LOCAL PROCESSING INFORMATION (OCLC); SERIES PART DESIGNATOR (RLIN)
c (OCLC) 04/03/1997
Holdings
Withdrawn status Lost status Source of classification or shelving scheme Damaged status Not for loan Home library Current library Shelving location Date acquired Total Checkouts Full call number Barcode Date last seen Copy number Price effective from Koha item type
    Dewey Decimal Classification     London London Journal article 14/09/1999   ABS45847 55427-1001 06/08/2019 1 06/08/2019 Law report