Damond Lock Grabowski & Partners v Laing Investments (Bracknell) Ltd (Record no. 35774)

MARC details
000 -LEADER
fixed length control field 01506cab a2200193 4500
001 - CONTROL NUMBER
control field ABS46497
008 - FIXED-LENGTH DATA ELEMENTS--GENERAL INFORMATION
fixed length control field 090401t1992 xxu||||| |||| 00| 0 eng d
035 ## - SYSTEM CONTROL NUMBER
System control number (Sirsi) u58555
041 ## - LANGUAGE CODE
Language code of text/sound track or separate title eng
245 ## - TITLE STATEMENT
Title Damond Lock Grabowski & Partners v Laing Investments (Bracknell) Ltd
260 ## - PUBLICATION, DISTRIBUTION, ETC.
Date of publication, distribution, etc. 1992
350 ## - PRICE (NR) (BK AM CF MU VM SE) [OBSOLETE]
Price 0
490 ## - SERIES STATEMENT
Series statement Construction Industry Law Letter
Volume/sequential designation 1992 CILL 762-765(4)
520 ## - SUMMARY, ETC.
Summary, etc. ORC 9 April 1992. L were the employers of a major project, D were the architects and C were the main contractors. Completion was delayed and C made a substantial claim for loss and expense. After consideration a payment of £288,000 was made by L to C. C considered this insufficient and commenced arbitration against L. L issued proceedings against C and L claiming against C a declaration that they had no contractual right to any further extension of time or loss and expense and against D damages for negligence and an indemnity against any claims of C`s which might be successful. L gave notice of arbitration to D and suggested that the same arbitrator be used, D objected however the same one was appointed. D objected again. The arbitrator continued with the arbitration and requested points of defence and counterclaims. D claimed misconduct by the arbitrator as he would not or could not fairly determine the issues in the arbitration on the evidence and arguements before him and kept req
650 ## - SUBJECT ADDED ENTRY--TOPICAL TERM
Topical term or geographic name entry element LOSS AND EXPENSE
690 ## - LOCAL SUBJECT ADDED ENTRY--TOPICAL TERM (OCLC, RLIN)
Topical term or geographic name as entry element ARBITRATION-CASE LAW
942 ## - ADDED ENTRY ELEMENTS (KOHA)
Suppress in OPAC 0
948 ## - LOCAL PROCESSING INFORMATION (OCLC); SERIES PART DESIGNATOR (RLIN)
c (OCLC) 04/03/1997
Holdings
Withdrawn status Lost status Source of classification or shelving scheme Damaged status Not for loan Home library Current library Shelving location Date acquired Total Checkouts Full call number Barcode Date last seen Copy number Price effective from Koha item type
    Dewey Decimal Classification     London London Journal article 14/09/1999   ABS46497 58555-1001 06/08/2019 1 06/08/2019 Law report