Slater V CA Duquemin Limited (Record no. 35882)

MARC details
000 -LEADER
fixed length control field 01587cab a2200205 4500
001 - CONTROL NUMBER
control field ABS46530
008 - FIXED-LENGTH DATA ELEMENTS--GENERAL INFORMATION
fixed length control field 090401t1992 xxu||||| |||| 00| 0 eng d
035 ## - SYSTEM CONTROL NUMBER
System control number (Sirsi) u58689
041 ## - LANGUAGE CODE
Language code of text/sound track or separate title eng
245 ## - TITLE STATEMENT
Title Slater V CA Duquemin Limited
260 ## - PUBLICATION, DISTRIBUTION, ETC.
Date of publication, distribution, etc. 1992
350 ## - PRICE (NR) (BK AM CF MU VM SE) [OBSOLETE]
Price 0
490 ## - SERIES STATEMENT
Series statement Construction Industry Law Letter
Volume/sequential designation 1992 CILL 761-762(2)
520 ## - SUMMARY, ETC.
Summary, etc. ORC 16 April 1992. In September 1986 S, the employer, entered into a Standard JCT Contract with Quantities (July 1977 revision) with C, the contractors, for the refurbishment and extension of a country house. The works overran the completition date. An emergency generator required by the contract was delivered in a damaged condition and had to be returned to the manufacturers. In January 1988 S barred C`s employees from site preventing them from doing any more work. S then employed further contractors at their own expense to complete the works. The generator was repaired but was rejected by L on the grounds that once damaged it might still be defective. The parties agreed that C were entitled to damages for disruption but other disputes were refered to arbitration. The arbitrator decided that S had repudiated the contract and that C were therefore entitled to an uncertificiated payment on the final account for the work which they carried out to the date of repudiation. He also held t
650 ## - SUBJECT ADDED ENTRY--TOPICAL TERM
Topical term or geographic name entry element MANAGEMENT-DISPUTE AVOIDANCE, MANAGEMENT AND RESOLUTION-DISPUTE MANAGEMENT AND RESOLUTION-ARBITRATION
650 ## - SUBJECT ADDED ENTRY--TOPICAL TERM
Topical term or geographic name entry element DELAYS
690 ## - LOCAL SUBJECT ADDED ENTRY--TOPICAL TERM (OCLC, RLIN)
Topical term or geographic name as entry element BUILDING AND CONSTRUCTION-CASE LAW
942 ## - ADDED ENTRY ELEMENTS (KOHA)
Suppress in OPAC 0
948 ## - LOCAL PROCESSING INFORMATION (OCLC); SERIES PART DESIGNATOR (RLIN)
c (OCLC) 04/03/1997
Holdings
Withdrawn status Lost status Source of classification or shelving scheme Damaged status Not for loan Home library Current library Shelving location Date acquired Total Checkouts Full call number Barcode Date last seen Copy number Price effective from Koha item type
    Dewey Decimal Classification     London London Journal article 14/09/1999   ABS46530 58689-1001 06/08/2019 1 06/08/2019 Law report