Imperial Chemical Industries v Bovis Construction and others (Record no. 37743)

MARC details
000 -LEADER
fixed length control field 01621cab a2200241 4500
001 - CONTROL NUMBER
control field ABS47206
008 - FIXED-LENGTH DATA ELEMENTS--GENERAL INFORMATION
fixed length control field 090401t1992 xxu||||| |||| 00| 0 eng d
035 ## - SYSTEM CONTROL NUMBER
System control number (Sirsi) u61047
041 ## - LANGUAGE CODE
Language code of text/sound track or separate title eng
245 ## - TITLE STATEMENT
Title Imperial Chemical Industries v Bovis Construction and others
260 ## - PUBLICATION, DISTRIBUTION, ETC.
Date of publication, distribution, etc. 1992
350 ## - PRICE (NR) (BK AM CF MU VM SE) [OBSOLETE]
Price 0
490 ## - SERIES STATEMENT
Series statement Construction Industry Law Letter
Volume/sequential designation 1992 CILL 776-778(3)
520 ## - SUMMARY, ETC.
Summary, etc. ORC 17 February 1992. This action arose out of refurbishment and reconstruction of I`s corporate headquarters. I brought proceedings against the management contractor, the architects and the consulting engineers. The essence of the case was that by reason of breach of their obligations to I by each defendant, including the failure to co-ordinate and supervise works, the works took much longer and cost much more than they should have done. No attempt was made in the schedule of claims to link any particular defendant to any particular loss. A global claim was made for the sum of £19m plus professional fees. I accepted a plea from the defendants that the claim for delay and disruption was inadequately pleaded and I was ordered to serve new particulars. This was also unsatisfactory and I was ordered to serve a Scott Schedule containing inter alia the alleged complaint, the defendant against whom the complaint was made, which clause of the agreement had been breached and the alleged fact
650 ## - SUBJECT ADDED ENTRY--TOPICAL TERM
Topical term or geographic name entry element CLAIMS
650 ## - SUBJECT ADDED ENTRY--TOPICAL TERM
Topical term or geographic name entry element DELAYS
650 ## - SUBJECT ADDED ENTRY--TOPICAL TERM
Topical term or geographic name entry element GOBAL CLAIMS
650 ## - SUBJECT ADDED ENTRY--TOPICAL TERM
Topical term or geographic name entry element SCHEDULE OF CLAIMS
650 ## - SUBJECT ADDED ENTRY--TOPICAL TERM
Topical term or geographic name entry element SCOTT SCHEDULES
690 ## - LOCAL SUBJECT ADDED ENTRY--TOPICAL TERM (OCLC, RLIN)
Topical term or geographic name as entry element BUILDING AND CONSTRUCTION-CASE LAW
942 ## - ADDED ENTRY ELEMENTS (KOHA)
Suppress in OPAC 0
948 ## - LOCAL PROCESSING INFORMATION (OCLC); SERIES PART DESIGNATOR (RLIN)
c (OCLC) 04/03/1997
Holdings
Withdrawn status Lost status Source of classification or shelving scheme Damaged status Not for loan Home library Current library Shelving location Date acquired Total Checkouts Full call number Barcode Date last seen Copy number Price effective from Koha item type
    Dewey Decimal Classification     London London Journal article 14/09/1999   ABS47206 61047-1001 06/08/2019 1 06/08/2019 Law report