Glenlion Construction Ltd v Guiness Trust (Record no. 5162)

MARC details
000 -LEADER
fixed length control field 01538cab a2200205 4500
001 - CONTROL NUMBER
control field ABS38052
008 - FIXED-LENGTH DATA ELEMENTS--GENERAL INFORMATION
fixed length control field 090401t1987 xxu||||| |||| 00| 0 eng d
035 ## - SYSTEM CONTROL NUMBER
System control number (Sirsi) u8389
041 ## - LANGUAGE CODE
Language code of text/sound track or separate title eng
245 ## - TITLE STATEMENT
Title Glenlion Construction Ltd v Guiness Trust
260 ## - PUBLICATION, DISTRIBUTION, ETC.
Date of publication, distribution, etc. 1987
350 ## - PRICE (NR) (BK AM CF MU VM SE) [OBSOLETE]
Price 0
490 ## - SERIES STATEMENT
Series statement Construction Industry Law Letter
Volume/sequential designation (1987) CILL 360-361(2)
520 ## - SUMMARY, ETC.
Summary, etc. ORC 28 July 1987 Appeal from an arbitration on a number of issues relating to a residential development in Bromley, under JCT 1963 with quantities (1977 edition). The questions of law raised were 1) whether on a true construction of clause 3 13 4 of the contract bills, the contractor should provide a programme for the whole of the works showing a completion date no later than the Date for Completion; 2) whether on a true construction of JCT 1963 clause 21 and clause 3 13 4 of the contract bills and so far as the programme showed a completion date before the date of completion, was the contractor entitled to carry out the works in accordance with his programme and so complete early and 3) was there an implied term in the contract to the effect that the employer and his architect should carry out their obligations so as to enable the contracto to complete early as he had planned. Held that the programme clause was a contract provision and in the light of the wording of JCT 1963 clause
650 ## - SUBJECT ADDED ENTRY--TOPICAL TERM
Topical term or geographic name entry element BUILT ENVIRONMENT-BUILDING CONTRACT FORMS
650 ## - SUBJECT ADDED ENTRY--TOPICAL TERM
Topical term or geographic name entry element CLAIMS
690 ## - LOCAL SUBJECT ADDED ENTRY--TOPICAL TERM (OCLC, RLIN)
Topical term or geographic name as entry element BUILDING AND CONSTRUCTION-CASE LAW
942 ## - ADDED ENTRY ELEMENTS (KOHA)
Suppress in OPAC 0
948 ## - LOCAL PROCESSING INFORMATION (OCLC); SERIES PART DESIGNATOR (RLIN)
c (OCLC) 04/03/1997
Holdings
Withdrawn status Lost status Source of classification or shelving scheme Damaged status Not for loan Home library Current library Shelving location Date acquired Total Checkouts Full call number Barcode Date last seen Copy number Price effective from Koha item type
    Dewey Decimal Classification     London London Journal article 14/09/1999   ABS38052 8389-1001 06/08/2019 1 06/08/2019 Law report