Damages clause altered (Record no. 5905)

MARC details
000 -LEADER
fixed length control field 01300cab a2200229 4500
001 - CONTROL NUMBER
control field ABS38240
008 - FIXED-LENGTH DATA ELEMENTS--GENERAL INFORMATION
fixed length control field 090401t1987 xxu||||| |||| 00| 0 eng d
035 ## - SYSTEM CONTROL NUMBER
System control number (Sirsi) u9450
041 ## - LANGUAGE CODE
Language code of text/sound track or separate title eng
100 ## - MAIN ENTRY--PERSONAL NAME
Personal name Jones, N.
245 ## - TITLE STATEMENT
Title Damages clause altered
260 ## - PUBLICATION, DISTRIBUTION, ETC.
Date of publication, distribution, etc. 1987
350 ## - PRICE (NR) (BK AM CF MU VM SE) [OBSOLETE]
Price 0
490 ## - SERIES STATEMENT
Series statement Building Design
Volume/sequential designation (857) 16 October 1987, 15(1)
520 ## - SUMMARY, ETC.
Summary, etc. Discusses the decision in Temloc Ltd v Errill Properties Ltd , CA 29 July 1987, see WB2334-10, and the interpretation of JCT 1980 clause 24 governing damages for non-completion of the contract. At issue was the effect on the liquidated damages clause caused by the employer`s insertion of "nil" against the item for liquidated damages in the appendix. Also reviews the decision in Cochrane and Another v Graham and Sibbald , Second Division 25 February 1987, see Abstract , in which the plaintiff house purchasers sued the defendant chartered surveyors for negligence . The surveyors carried out a survey report on a house purchased by the plaintiffs, the report contained no mention of the dry rot later discovered.
650 ## - SUBJECT ADDED ENTRY--TOPICAL TERM
Topical term or geographic name entry element BUILT ENVIRONMENT-BUILDING CONTRACT FORMS
650 ## - SUBJECT ADDED ENTRY--TOPICAL TERM
Topical term or geographic name entry element CLAIMS
650 ## - SUBJECT ADDED ENTRY--TOPICAL TERM
Topical term or geographic name entry element PROFESSIONAL NEGLIGENCE
690 ## - LOCAL SUBJECT ADDED ENTRY--TOPICAL TERM (OCLC, RLIN)
Topical term or geographic name as entry element BUILT ENVIRONMENT-BUILDING CONTRACT FORMS
942 ## - ADDED ENTRY ELEMENTS (KOHA)
Suppress in OPAC 0
948 ## - LOCAL PROCESSING INFORMATION (OCLC); SERIES PART DESIGNATOR (RLIN)
c (OCLC) 04/03/1997
Holdings
Withdrawn status Lost status Source of classification or shelving scheme Damaged status Not for loan Home library Current library Shelving location Date acquired Total Checkouts Full call number Barcode Date last seen Copy number Price effective from Koha item type
    Dewey Decimal Classification     London London Journal article 14/09/1999   ABS38240 9450-1001 06/08/2019 1 06/08/2019 Journal article