Quietfield Ltd v Vascroft Construction Ltd (Record no. 78512)

MARC details
000 -LEADER
fixed length control field 02184cab a22002295a 4500
001 - CONTROL NUMBER
control field L136967
008 - FIXED-LENGTH DATA ELEMENTS--GENERAL INFORMATION
fixed length control field 070307e2006 xxk 000 0 eng d
035 ## - SYSTEM CONTROL NUMBER
System control number (Sirsi) u136967
041 0# - LANGUAGE CODE
Language code of text/sound track or separate title eng
245 ## - TITLE STATEMENT
Title Quietfield Ltd v Vascroft Construction Ltd
260 ## - PUBLICATION, DISTRIBUTION, ETC.
Date of publication, distribution, etc. 2006
520 ## - SUMMARY, ETC.
Summary, etc. [2006] EWCA Civ 1737, 20 December 2006. Appeal by Q against the dismissal of its claim for summary judgment ([2006 EWHC 174 (TCC), L132952] to enforce an adjudicator's decision against the respondent contractor (V). The key issue was whether the adjudicator should have considered V?s revised claim. V's original claim for an extension of time in the first adjudication, which relied on two brief claim letters, was rejected. In the second adjudication V contended it was not liable to pay Q liquidated and ascertained damages because V had been entitled to more time. On this occasion V produced detailed claim of 400 pages. The adjudicator refused to consider V's argument, in accordance with the Housing Grants, Construction and Regeneration Act 1996, as the issue of extension of time had been determined in the first adjudication. An award in Q's favour was granted, which V declined to pay, and Q issued proceedings. "Held": appeal dismissed. The alleged entitlement to an extension of time relied on in the second adjudication was substantially different from the claim put forward and rejected in the first adjudication. This decision was in the context of an issue (extension of time) where the contract terms allowed certain arguments to be revisited.
590 ## - LOCAL NOTE (RLIN)
Local note KA
650 24 - SUBJECT ADDED ENTRY--TOPICAL TERM
Topical term or geographic name entry element SCHEME FOR CONSTRUCTION CONTRACTS
650 24 - SUBJECT ADDED ENTRY--TOPICAL TERM
Topical term or geographic name entry element QUIETFIELD LTD V VASCROFT CONTRACTORS LTD
650 24 - SUBJECT ADDED ENTRY--TOPICAL TERM
Topical term or geographic name entry element SCHEME FOR CONSTRUCTION CONTRACTS (ENGLAND AND WALES) REGULATIONS 1998
650 24 - SUBJECT ADDED ENTRY--TOPICAL TERM
Topical term or geographic name entry element HOUSING GRANTS, CONSTRUCTION AND REGENERATION ACT 1996
651 #4 - SUBJECT ADDED ENTRY--GEOGRAPHIC NAME
Geographic name England and Wales
Chronological subdivision 1543-
690 ## - LOCAL SUBJECT ADDED ENTRY--TOPICAL TERM (OCLC, RLIN)
Topical term or geographic name as entry element MANAGEMENT-DISPUTE AVOIDANCE, MANAGEMENT AND RESOLUTION-DISPUTE MANAGEMENT AND RESOLUTION-ALTERNATIVE DISPUTE RESOLUTION-ADJUDICATION
856 40 - ELECTRONIC LOCATION AND ACCESS
Uniform Resource Identifier <a href="https://www.bailii.org./cgi-bin/markup.cgi?doc=/ew/cases/EWCA/Civ/2006/1737.html">https://www.bailii.org./cgi-bin/markup.cgi?doc=/ew/cases/EWCA/Civ/2006/1737.html</a>
Public note View the judgment free of charge at www.bailii.org...
942 ## - ADDED ENTRY ELEMENTS (KOHA)
Suppress in OPAC 0
Holdings
Withdrawn status Lost status Source of classification or shelving scheme Damaged status Not for loan Home library Current library Shelving location Date acquired Total Checkouts Full call number Barcode Date last seen Copy number Price effective from Koha item type
    Dewey Decimal Classification     Virtual Virtual Online 07/03/2007   ONLINE PUBLICATION 136967-2001 06/08/2019 1 06/08/2019 Law report