| 000 | 01289cam a22002775a 4500 | ||
|---|---|---|---|
| 001 | L130761 | ||
| 002 | 8821 | ||
| 008 | 050825s2006 xxk f g 000 0 eng d | ||
| 020 | _a0418829209 | ||
| 035 | _a(Sirsi) u130761 | ||
| 041 | 0 | _aeng | |
| 050 | 0 | 4 | _a692.8 $2 18 |
| 110 | 2 |
_aJoint Contracts Tribunal _93664 |
|
| 240 | _aPPC 2006 | ||
| 245 | 0 | 0 | _aPrime cost building contract |
| 260 |
_aLondon _bSweet and Maxwell _c2006 |
||
| 300 |
_aiv, 84p. _c30cm |
||
| 350 | _a34.95 | ||
| 505 | 2 | _aDefinitions and interpretations -- Carrying out the works -- Control of the works -- Payment -- Injury, damage and insurance -- Assignment and collateral warranties -- Termination -- Settlement of disputes | |
| 520 | _aDiscusses the obligations and duties of contractors, employers and surveyors. Explains possession, supply of documents, fees, patent rights, issues relating to completion date, the Construction (Design and Management) Regulations, retention, loss and expenses, collateral warranties and schedules. | ||
| 650 | 2 | 4 | _aARBITRATION ACT 1996 |
| 650 | 2 | 4 | _aJCT PRIME COST BUILDING CONTRACT (2006 EDITION) |
| 651 | 4 |
_aUnited Kingdom _y |
|
| 690 | _aBUILT ENVIRONMENT-BUILDING CONTRACT FORMS-STANDARD FORMS OF BUILDING CONTRACT-JOINT CONTRACTS TRIBUNAL CONTRACTS | ||
| 942 | _n0 | ||
| 999 |
_c104564 _d104564 |
||