000			01587cab a2200205 4500
001			ABS46530
008			090401t1992 xxu||||| |||| 00| 0 eng d
035			_a(Sirsi) u58689
041			_aeng
245			_aSlater V CA Duquemin Limited
260			_c1992
350			_a0
490			_aConstruction Industry Law Letter _v1992 CILL 761-762(2)
520			_aORC 16 April 1992. In September 1986 S, the employer, entered into a Standard JCT Contract with Quantities (July 1977 revision) with C, the contractors, for the refurbishment and extension of a country house. The works overran the completition date. An emergency generator required by the contract was delivered in a damaged condition and had to be returned to the manufacturers. In January 1988 S barred C`s employees from site preventing them from doing any more work. S then employed further contractors at their own expense to complete the works. The generator was repaired but was rejected by L on the grounds that once damaged it might still be defective. The parties agreed that C were entitled to damages for disruption but other disputes were refered to arbitration. The arbitrator decided that S had repudiated the contract and that C were therefore entitled to an uncertificiated payment on the final account for the work which they carried out to the date of repudiation. He also held t
650			_aMANAGEMENT-DISPUTE AVOIDANCE, MANAGEMENT AND RESOLUTION-DISPUTE MANAGEMENT AND RESOLUTION-ARBITRATION
650			_aDELAYS
690			_aBUILDING AND CONSTRUCTION-CASE LAW
942			_n0
948			_c04/03/1997
999			_c35882 _d35882