000			01167cab a2200277 4500
001			ABS47969
008			090401t1993 xxu||||| |||| 00| 0 eng d
035			_a(Sirsi) u64239
041			_aeng
100			_aCornes, D.
245			_aLate decision
260			_c1993
350			_a0
490			_aNew Builder _v(164) 26 February 1993, 18(1)
520			_aCites "Balfour Beatty v Chestermount Properties" as example of where a contractor has passed the extended completion date, is causing delay, and is then instructed for a variation which has the effect of delaying completion further. In upholding the arbitrator`s decision in C`s favour, the court ruled that the developer`s architect had the right to grant extensions of time during a period of culpable delay by B, if employing the `net` basis of deductions rather than the `gross`.
650			_aBUILT ENVIRONMENT-BUILDING CONTRACT FORMS
650			_aCLAIMS
650			_aCOMPLETION DATE
650			_aCONTRACT CLAIMS
650			_aDEDUCTIONS
650			_aDELAY
650			_aEXTENSIONS OF TIME
690			_aBUILT ENVIRONMENT-BUILDING CONTRACT FORMS
942			_n0
948			_c04/03/1997
999			_c39995 _d39995