| 000 | 01068cab a2200301 4500 | ||
|---|---|---|---|
| 001 | ABS48786 | ||
| 008 | 090401t1993 xxu||||| |||| 00| 0 eng d | ||
| 035 | _a(Sirsi) u68539 | ||
| 041 | _aeng | ||
| 100 | _aProctor, N. | ||
| 245 | _aContractors` escape route blocked up | ||
| 260 | _c1993 | ||
| 350 | _a0 | ||
| 490 |
_aBuilding _v258(22) 28 May 1993, 34-35(2) |
||
| 520 | _aSummarises "Balfour Beatty Building v Chestermount Properties" (1993), on the issue of calculation of liquidated damages for delay by the contractor, when a variation has been issued after the completion date. The court decision did not allow contractors to avoid liquidated damages in these circumstances. | ||
| 650 | _aBUILT ENVIRONMENT-BUILDING CONTRACT FORMS | ||
| 650 | _aCLAIMS | ||
| 650 | _aCOMPLETION | ||
| 650 | _aDELAY | ||
| 650 | _aEXTENSION OF TIME | ||
| 650 | _aJCT 1980 CL25.3.1 | ||
| 650 | _aJCT 1980 CL25.3.5 | ||
| 650 | _aLIQUIDATED DAMAGES | ||
| 650 | _aVARIATION | ||
| 690 | _aBUILDING AND CONSTRUCTION-CASE LAW | ||
| 942 | _n0 | ||
| 948 | _c04/03/1997 | ||
| 999 |
_c43000 _d43000 |
||