000			01300cab a2200229 4500
001			ABS38240
008			090401t1987 xxu||||| |||| 00| 0 eng d
035			_a(Sirsi) u9450
041			_aeng
100			_aJones, N.
245			_aDamages clause altered
260			_c1987
350			_a0
490			_aBuilding Design _v(857) 16 October 1987, 15(1)
520			_aDiscusses the decision in Temloc Ltd v Errill Properties Ltd , CA 29 July 1987, see WB2334-10, and the interpretation of JCT 1980 clause 24 governing damages for non-completion of the contract. At issue was the effect on the liquidated damages clause caused by the employer`s insertion of "nil" against the item for liquidated damages in the appendix. Also reviews the decision in Cochrane and Another v Graham and Sibbald , Second Division 25 February 1987, see Abstract , in which the plaintiff house purchasers sued the defendant chartered surveyors for negligence . The surveyors carried out a survey report on a house purchased by the plaintiffs, the report contained no mention of the dry rot later discovered.
650			_aBUILT ENVIRONMENT-BUILDING CONTRACT FORMS
650			_aCLAIMS
650			_aPROFESSIONAL NEGLIGENCE
690			_aBUILT ENVIRONMENT-BUILDING CONTRACT FORMS
942			_n0
948			_c04/03/1997
999			_c5905 _d5905