000			01670cam a2200265 4500
001			ABS62948
008			000000n2000 000 0 eng u
035			_a(Sirsi) u108938
100			_aButton, R.
245			_aRetrospective delay analyses: a recent case history
260			_c2000
490			_aCSM (Chartered Surveyor Monthly) _vOctober 2000, 34(1)
520			_aRecommends that surveyors, architects and engineers with responsibility for analysing the causes of delay, for the purposes of granting extensions of time or paying additional costs for prolongation or disruption, take note of a number of important recent judgements. Contains a brief summary of these cases. In "Ascon Contracting Limited v Alfred McAlpine Construction Isle of Man Limited", the court held that the float was neutral as between the various defaulting parties. In the case of "Henry Boot Construction (UK) Limited v Malmaison Hotel (Manchester) Ltd" the court found that the architect is entitled to consider the contractor responsible for concurrent delays when establishing whether or not a relevant event had in fact caused delay.
590			_aABS
650			_aDELAY ANALYSIS
650			_aDISRUPTION
650			_aADDITIONAL COSTS
650			_aASCON CONTRACTING LTD V ALFRED MCALPINE CONSTRUCTION (ISLE OF MAN)
650			_aHENRY BOOT CONSTRUCTION (UK) V MALMAISON HOTEL (MANCHESTER)
650			_aMANAGEMENT-DISPUTE AVOIDANCE, MANAGEMENT AND RESOLUTION-DISPUTE MANAGEMENT AND RESOLUTION-ALTERNATIVE DISPUTE RESOLUTION-ADJUDICATION
650			_aCONTRACT CLAIMS
690			_aBUILT ENVIRONMENT-BUILDING CONTRACT FORMS
700			_aMills, R.
942			_n0
999			_c65046 _d65046